Sunday, October 17, 2021

Legals for September, 7 2021

| September 7, 2021 12:00 AM

PUBLIC NOTICE The Idaho Department of Environmental Quality is soliciting bids to supply hydrated lime for the Bunker Hill Central Treatment Plant in Kellogg Idaho. Qualified firms interested in providing a bid should review the ITB documents at for more information, contact: Keri St. John at the Kellogg Office (208) 784-3620 or Keith Thomas at the Boise DEQ State Office: (208) 373-0119. SHO LEGAL 3941 AD#480563 AUGUST 27, 31, SEPTEMBER 3, 7, 10, 14, 2021

INVITATION TO BID NOTICE TO CONTRACTORS: Sealed bid proposals will be received - BY: THE BOARD OF TRUSTEES FOR:PINEHURST ELEMENTARY SCHOOL CAFETERIA ADDITION AND TITLE ONE REMODEL Kellogg Joint School District No 391 201 S Third St Pinehurst, Idaho 83850 AS FOLLOWS: 1) General Construction Prime Bids for this project shall be received as follows: BIDS shall be due THURSDAY, SEPTEMBER 23, 2021 at 3:00 p.m. at the Kellogg Joint School District Central Office at 800 Bunker Avenue, Kellogg, Idaho 83837. PRE-BID CONFERENCE: shall be THURSDAY, SEPTEM BER 16, 2021 at 3:00 p.m. at PINEHURST ELEMENTARY SCHOOL located at 201 S THIRD STREET PINEHURST, IDAHO. (Bids shall include all general, electrical, and mechanical work shown and/or specified, under one General bid proposal). 2) Bids shall be publicly opened and read aloud on SEPTEM- BER 23, 2021 at 3:00 p.m. 3) Bidders and patrons of the Kellogg Joint School District No 391 are invited to attend the bid opening. 4) Plans and specifications, bid forms, forms of agreement, etc., may be obtained by bona fide general bidders, and bona fide mechanical, electrical, and plumbing sub-bidders, and supplies at www.longwelltrappplanroom. com. Complete bidding documents for this project are avail able in electronic form only, by downloading the documents (at no charge) or by purchasing hard copy documents (at bidder's expense) from the plan room noted above. To be added to the official plan holders list and ensure notification of addenda, bidders must register at the plan room noted above. The Architect and Owner will not be responsible for partial sets of documents obtained from reprographics companies or plan centers. Any and all errors or omissions resulting from the failure of the General Contractor, Subcontractor, or material supplier to become familiar with the documents in their entirety will be corrected at the Contractor's expense. Questions regarding this Notice of Advertisement for bids shall be directed to the office of Longwell + Trapp Archi tects, 8382 N Wayne Dr #204, Hayden, ID 83835. Architect phone number 208.772.0503. Project Architect Cory Trapp, AIA. Bid forms, bidder's instructions, drawings, and specifications may be examined at the following locations: Abadan Plan Room, Spokane, WA Spokane Regional Plan Center, Spokane, WA Associated Builders & Contractors, Spokane, WA Longwell + Trapp Architects, Hayden, ID 5) Idaho law requires that all bidders have an Idaho Public Works Contractor's License, as provided for by the Public Works Contractors License Act. 6) Bids must be made upon the form furnished, must be ac- companied by a bid bond or other surety in the amount of 5% of the total bid amount, and cannot be withdrawn until thirty (30) days after the above stated times of opening. 7) The Board of Trustees, Kellogg Joint School District No 391, Kellogg, Idaho reserves the right to reject any and all bids, to waive any informalities and to award the bid to the responsive bidder that the School District deems is in the best interest of the School District. In the event the School District elects to award the bid to other than the lowest re- sponsive bidder, the School District will declare its reasons on the record and communicate those reasons in writing to all person having submitted a competing bid. If there are two or more identical responsive bids from which the School District elects to make the selection, the School District shall have the discretion to award the bid in any manner deemed fair and equitable and in the best interest of the School District. SHO LEGAL 3951 AD#482942 SEPTEMBER 7, 14, 2021

NOTICE OF SHERIFF'S SALE Under and by virtue of a Writ of Execution on Judgment of Foreclosure issued on July 16, 2021, and an Order of Sale of Foreclosure issued on July 16, 2021, out of the District Court of the First Judicial District of the State of Idaho, in and for the County of Shoshone in the case of: NATIONSTAR MORTGAGE LLC D/B/A CHAMPION MORTGAGE COMPANY, Plaintiff, v. THE UNKNOWN HEIRS, ASSIGNS AND DEVISEES OF CHESTER L. CROSS; LINDA SUE TYREE CROSS AKA LINDA TYREE CROSS; SECRETARY OF HOUSING AND URBAN DEVELOPMENT; AND DOES 1 THROUGH 20, et al., Defendants. Case No. CV40-21-0144 NOTICE OF SALE Date of Sale: September 28, 2021 Time of Sale: 10:00 am Place of Sale: Shoshone County Court House 700 Bank Street Wallace, ID 83873 NOTICE IS HEREBY GIVEN, that on the 28th day of September 2021, at 10:00 o'clock am of said day, at Shoshone County Court House 700 Bank St, Wallace ID 83873, I am commanded and required to proceed to notice for sale to sell at public auction the real property described in said Order for Sale of Foreclosure and Writ of Execution and to apply the proceeds of such sale to the satisfaction of said Judgment and Decree of Foreclosure with interest thereon and my fees and costs, all payable at time of sale to the highest bidder, for the following described property, situated in Shoshone County, Idaho: 203 W. Mission Ave, Kellogg, ID 83837 and legally described as follows: LOTS 1 AND 2 IN BLOCK 4 OF KELLOGG, SUNNYSIDE ADDITION, ACCORDING TO THE OFFICIAL PLAT THEREOF, FILED IN OFFICIAL RECORDS OF SHOSHONE COUNTY, IDAHO. The sale will be made without covenant or warranty regarding title, possession, or encumbrances to satisfy the obligation of Defendants pursuant to the Judgment entered in this matter, and recorded in the official records of Shoshone County. The real property sold at the sale shall be subject to the redemption rights of redemptioners, as that term is defined in Idaho Code Section 11-402, may redeem the property from the purchaser within six months after the sale, upon paying the purchaser the amount of their purchase, with interest on that amount at the rate allowed by Idaho Code from the date of the sale to the date of redemption, together with the amount of any assessment or taxes which the purchaser may have paid after the commencement of the action and which are not included in the judgment and interest allowed pursuant to Idaho Code Section. In the event the purchaser is a creditor having a prior lien to that of the redemptioners, other than the judgment under which the purchase is made, the purchaser will also be entitled to payment of that lien amount with interest at the rate allowed in Idaho Code Section18-22-104(1). The Sheriff, by Certificate of Sale, will transfer all right, title and interest of the judgment debtors in and to the property at the time of execution of attachment was levied. DATED this 26th day of August, 2021. DEPUTY SHERIFF OF SHOSHONE COUNTY, IDAHO By: Kattie D. Ross NOTE: THE SHERIFF'S OFFICE DOES NOT GUARANTEE CLEAR TITLE OR GUARANTEE CONTINUED POSSESSORY RIGHTS. SHO LEGAL 3953 AD# 483017 SEPTEMBER 7, 14, 21, 2021