Legals for September, 14 2021

CITY OF WALLACE F/Y 2020-21 AMENDED APPROPRIATION ORDINANCE ORDINANCE 2021-05 AN ORDINANCE BEING THE AMENDED APPROPRIATION BILL OF THE CITY OF WALLACE, COUNTY OF SHOSHONE, STATE OF IDAHO, FOR THE FISCAL YEAR COMMENCING OCTOBER 1, 2020 AND ENDING SEPTEMBER 30, 2021, AND BY WHICH THE CORPORATE AUTHORITIES OF SAID CITY APPROPRIATE SUCH SUMS OF MONEY AS ARE DEEMED NECESSARY TO DEFRAY THE EXPENSES AND LIABILITIES OF SAID CITY, FOR THE SAID FISCAL YEAR, PURSUANT TO THE PROVISION OF SECTION 50-1003, IDAHO CODE. BE IT ORDAINED BY THE MAYOR AND COUNCIL OF THE CITY OF WALLACE, IDAHO: SECTION 1. That Ordinance 2021-05, the appropriation ordinance for the City of Wallace, Idaho for the fiscal year beginning October 1, 2020 be and the same is hereby amended to reflect additional expense for the General Fund, Street Fund, Library Fund and Parks and Recreation Fund. The following sums are hereby appropriated. GENERAL FUND 573,622.00 611,188.00 STREET FUND 904,452.00 915,346.00 LIBRARY FUND 90,164.00 90,789.00 PARKS & REC FUND 335,683.00 1,004,378.00 SEWER FUND 235,099.00 INSURANCE FUND 43,390.00 TOTAL PROPOSED EXPENDITURES 2,182,410.00 2,900,190.00 SECTION 2. This ordinance shall be in force and effect from and after its passage, approval and publication. Passed under the suspension of the rules, upon which a roll call vote was duly taken, enacted as an Ordinance of the City of Wallace at a regular meeting of the City Council held on Wednesday the 8th of September, 2021. /S/ Lynn Mogensen, Mayor ATTEST: /S/ Kristina Larson Clerk/Treasurer SHO LEGAL 3956 AD#484120 SEPTEMBER 14, 2021

CITY OF WALLACE F/Y 2021-22 APPROPRIATION ORDINANCE ORDINANCE 2021-06 AN ORDINANCE BEING THE ANNUAL APPROPRIATION BILL OF THE CITY OF WALLACE, COUNTY OF SHOSHONE, STATE OF IDAHO, FOR THE FISCAL YEAR COMMENCING OCTOBER 1, 2021 AND ENDING SEPTEMBER 30, 2022, AND BY WHICH THE CORPORATE AUTHORITIES OF SAID CITY APPROPRIATE SUCH SUMS OF MONEY AS ARE DEEMED NECESSARY TO DEFRAY THE EXPENSES AND LIABILITIES OF SAID CITY, FOR THE SAID FISCAL YEAR, PURSUANT TO THE PROVISION OF SECTION 50-1003, IDAHO CODE. BE IT ORDAINED BY THE MAYOR AND COUNCIL OF THE CITY OF WALLACE, IDAHO: SECTION 1. That there is appropriated out of the city treasury, for the purpose of defraying the necessary expenses and liabilities of the City of Wallace, Idaho for the year commencing October 1, 2021, and ending September 30, 2022 the sum of sums of money or so much thereof as may be necessary for the following purpose in the amount shown to wit: GENERAL FUND 644,473.00 STREET FUND 497,432.00 LIBRARY FUND 81,501.00 PARKS & REC FUND 258,275.00 SEWER FUND 246,869.00 INSURANCE FUND 72,865.00 TOTAL PROPOSED EXPENDITURES 1,801,415.00 SECTION 2. This ordinance shall be in force and effect from and after its passage, approval and publication. Passed under the suspension of the rules, upon which a roll call vote was duly taken, enacted as an Ordinance of the City of Wallace at a regular meeting of the City Council held on Wednesday the 8th of September 2021. /S/ Lynn Mogensen, Mayor ATTEST: /S/ Kristina Larson Clerk/Treasurer SHO LEGAL 3957 AD#484124 SEPTEMBER 14, 2021

PUBLIC NOTICE The Idaho Department of Environmental Quality is soliciting bids to supply hydrated lime for the Bunker Hill Central Treatment Plant in Kellogg Idaho. Qualified firms interested in providing a bid should review the ITB documents at http://www.deq.idaho.gov/about-deq/vendor-opportunities/ for more information, contact: Keri St. John at the Kellogg Office (208) 784-3620 or Keith Thomas at the Boise DEQ State Office: (208) 373-0119. SHO LEGAL 3941 AD#480563 AUGUST 27, 31, SEPTEMBER 3, 7, 10, 14, 2021

INVITATION TO BID NOTICE TO CONTRACTORS: Sealed bid proposals will be received - BY: THE BOARD OF TRUSTEES FOR:PINEHURST ELEMENTARY SCHOOL CAFETERIA ADDITION AND TITLE ONE REMODEL Kellogg Joint School District No 391 201 S Third St Pinehurst, Idaho 83850 AS FOLLOWS: 1) General Construction Prime Bids for this project shall be received as follows: BIDS shall be due THURSDAY, SEPTEMBER 23, 2021 at 3:00 p.m. at the Kellogg Joint School District Central Office at 800 Bunker Avenue, Kellogg, Idaho 83837. PRE-BID CONFERENCE: shall be THURSDAY, SEPTEM BER 16, 2021 at 3:00 p.m. at PINEHURST ELEMENTARY SCHOOL located at 201 S THIRD STREET PINEHURST, IDAHO. (Bids shall include all general, electrical, and mechanical work shown and/or specified, under one General bid proposal). 2) Bids shall be publicly opened and read aloud on SEPTEM- BER 23, 2021 at 3:00 p.m. 3) Bidders and patrons of the Kellogg Joint School District No 391 are invited to attend the bid opening. 4) Plans and specifications, bid forms, forms of agreement, etc., may be obtained by bona fide general bidders, and bona fide mechanical, electrical, and plumbing sub-bidders, and supplies at www.longwelltrappplanroom. com. Complete bidding documents for this project are avail able in electronic form only, by downloading the documents (at no charge) or by purchasing hard copy documents (at bidder's expense) from the plan room noted above. To be added to the official plan holders list and ensure notification of addenda, bidders must register at the plan room noted above. The Architect and Owner will not be responsible for partial sets of documents obtained from reprographics companies or plan centers. Any and all errors or omissions resulting from the failure of the General Contractor, Subcontractor, or material supplier to become familiar with the documents in their entirety will be corrected at the Contractor's expense. Questions regarding this Notice of Advertisement for bids shall be directed to the office of Longwell + Trapp Archi tects, 8382 N Wayne Dr #204, Hayden, ID 83835. Architect phone number 208.772.0503. Project Architect Cory Trapp, AIA. Bid forms, bidder's instructions, drawings, and specifications may be examined at the following locations: www.longwelltrappplanroom.com Abadan Plan Room, Spokane, WA Spokane Regional Plan Center, Spokane, WA Associated Builders & Contractors, Spokane, WA Longwell + Trapp Architects, Hayden, ID 5) Idaho law requires that all bidders have an Idaho Public Works Contractor's License, as provided for by the Public Works Contractors License Act. 6) Bids must be made upon the form furnished, must be ac- companied by a bid bond or other surety in the amount of 5% of the total bid amount, and cannot be withdrawn until thirty (30) days after the above stated times of opening. 7) The Board of Trustees, Kellogg Joint School District No 391, Kellogg, Idaho reserves the right to reject any and all bids, to waive any informalities and to award the bid to the responsive bidder that the School District deems is in the best interest of the School District. In the event the School District elects to award the bid to other than the lowest re- sponsive bidder, the School District will declare its reasons on the record and communicate those reasons in writing to all person having submitted a competing bid. If there are two or more identical responsive bids from which the School District elects to make the selection, the School District shall have the discretion to award the bid in any manner deemed fair and equitable and in the best interest of the School District. SHO LEGAL 3951 AD#482942 SEPTEMBER 7, 14, 2021

Shoshone County Ambulance Service District Benefits Proposed Budget October 1, 2021 to September 30, 2022 Anticipated Revenues Ambulance Service Revenues 689,172 Local Property Levy 473,690 State Grants 25,000 Total Anticipated Revenues 1,187,862 Anticipated Expenses Labor Expense 733,366 Operating Expense 166,181 Asset Expense 283,217 Total Anticipated Expenses 1,253,824 Shoshone County Ambulance Service District will hold a public hearing to approve the proposed budget on September 20, 2021 at 6pm at 58738 Silver Valley Road in Osburn Idaho LEGAL 3954/ AD 483608 SEPT 10, 14, 2021

NOTICE OF PUBLIC HEARING SHOSHONE COUNTY FIRE PROTECTION DISTRICT 1 PROPOSED AMENDED BUDGET FOR FISCAL YEAR 2020-2021 Notice is hereby given that the Board of Commissioners of Shoshone County Fire Protection District 1 (SCFPD1), Osburn, Shoshone County, Idaho will hold a public hearing for consideration of the proposed budget for the fiscal period October 1, 2020 - September 30, 2021, all pursuant to the provisions of Section 31-1422, Idaho Code. The hearing will be held at 58738 Silver Valley Road, Osburn, Idaho at 5:00 p.m. on September 20, 2021. All interested residents are invited to appear and offer testimony concerning the proposed budget. Copies of the proposed budget are available at SCFPD1 during regular office hours, 8:00a.m. - 4:00 p.m., Monday through Friday. SCFPD1 is accessible to persons with disabilities. Anyone desiring accommodations for disabilities related to the budget documents or the hearing, please contact the SCFPD1 at (208) 752-1101 at least 48 hours prior to the hearing. PROPOSED AMENDED BUDGET FISCAL YEAR 2020-2021 REVENUE: Property Tax Levy 324,450 Sales Tax 32,000 Shoshone County EMS 219,600 City of Wallace 81,079 Bond Collection 107,692 Misc. Revenue 690,000 TOTAL ESTIMATED REVENUE 1,454,821 EXPENSE: Labor 379,500 Insurance Total 120,600 Bond Payment 107,692 New Construction 20,000 Other Miscellaneous 827,029 TOTAL EXTIMATED EXPENSE 1,454,821 Dated this 7th day of September 7, 2021 Lisa D. Millard, Secretary SHO LEGAL 3955 AD#484116 SEPTEMBER 14, 2021

SHOSHONE COUNTY, IDAHO BOARD OF COUNTY COMMISSIONERS NOTICE OF PUBLIC HEARING NOTICE IS HEREBY GIVEN THAT THE SHOSHONE COUNTY BOARD OF COMMISSIONERS will, at a meeting to be held on October 14, 2021 at 10:30 A.M. at the office of the Board of County Commissioners, hold a public hearing on the petition presented by Jeff and Gina Cope to vacate and abandon a portion of Potlatch Road in excess of a 100' corridor, adjacent to Lot 7 as described in Instrument No. 503470, Records of Shoshone County, Block 6, Herrick Park, filed as Instrument No. 203899, Shoshone County, Idaho. The hearing will be held in the Board of Commissioners Conference Room, 700 Bank St, Wallace, Idaho at which time anyone may appear in support of or in opposition to the proposed abandonment of the area as described hereinabove. The hearing will be held in a facility that is accessible to persons with disabilities. Special accommodations will be available, upon request, five (5) days prior to the hearing in a format that is usable to persons with disabilities. For more information, contact the County Clerk at (208) 752-3331. Written testimony expressing support, opposition, or neutrality towards this proposal or other information will be accepted until 5:00 p.m. (PST) on October 13th, 2021. All other materials must be submitted at the Public Hearing. For all submissions greater than two (2) pages, the submitter shall provide eight (8) copies. Additionally, all information presented and or submitted shall become the property of Shoshone County and will be on file at the Planning Administration office. Additional information concerning the above item(s) may be obtained from the Shoshone County Planning Administration Office, County Courthouse, 700 Bank Street Suite 25, Wallace, Idaho (208) 752-8891 or Fax (208) 556-5135 or E-mail: pz@co.shoshone.id.us. S/Dan Martinsen Dan Martinsen, Administrator SHO LEGAL 3958 AD#484140 SEPTEMBER 14, 21, OCTOBER 5, 2021

SHOSHONE COUNTY, IDAHO BOARD OF COUNTY COMMISSIONERS NOTICE OF PUBLIC HEARING NOTICE IS HEREBY GIVEN THAT THE SHOSHONE COUNTY BOARD OF COMMISSIONERS will, at a meeting to be held on October 14, 2021 at 10:00 A.M at the office of the Board of County Commissioners, hold a public hearing on the petition presented by Tri-State Consulting Engineers, Inc. to vacate and abandon a portion of Potlatch Road in excess of a 100' corridor, adjacent to Lot 1 as described in Instrument No. 509967, Records of Shoshone County, Block 6, Herrick Park, filed as Instrument No. 203899, Shoshone County, Idaho. The hearing will be held in the Board of Commissioners Conference Room, 700 Bank St, Wallace, Idaho at which time anyone may appear in support of or in opposition to the proposed abandonment of the area as described hereinabove. The hearing will be held in a facility that is accessible to persons with disabilities. Special accommodations will be available, upon request, five (5) days prior to the hearing in a format that is usable to persons with disabilities. For more information, contact the County Clerk at (208) 752-3331. Written testimony expressing support, opposition, or neutrality towards this proposal or other information will be accepted until 5:00 p.m. (PST) on October 13th, 2021. All other materials must be submitted at the Public Hearing. For all submissions greater than two (2) pages, the submitter shall provide eight (8) copies. Additionally, all information presented and or submitted shall become the property of Shoshone County and will be on file at the Planning Administration office. Additional information concerning the above item(s) may be obtained from the Shoshone County Planning Administration Office, County Courthouse, 700 Bank Street Suite 25, Wallace, Idaho (208) 752-8891 or Fax (208) 556-5135 or E-mail: pz@co.shoshone.id.us. S/Dan Martinsen Dan Martinsen, Administrator SHO LEGAL 3959 AD#484141 SEPTEMBER 14, 21, OCTOBER 5, 2021

NOTICE OF SHERIFF'S SALE Under and by virtue of a Writ of Execution on Judgment of Foreclosure issued on July 16, 2021, and an Order of Sale of Foreclosure issued on July 16, 2021, out of the District Court of the First Judicial District of the State of Idaho, in and for the County of Shoshone in the case of: NATIONSTAR MORTGAGE LLC D/B/A CHAMPION MORTGAGE COMPANY, Plaintiff, v. THE UNKNOWN HEIRS, ASSIGNS AND DEVISEES OF CHESTER L. CROSS; LINDA SUE TYREE CROSS AKA LINDA TYREE CROSS; SECRETARY OF HOUSING AND URBAN DEVELOPMENT; AND DOES 1 THROUGH 20, et al., Defendants. Case No. CV40-21-0144 NOTICE OF SALE Date of Sale: September 28, 2021 Time of Sale: 10:00 am Place of Sale: Shoshone County Court House 700 Bank Street Wallace, ID 83873 NOTICE IS HEREBY GIVEN, that on the 28th day of September 2021, at 10:00 o'clock am of said day, at Shoshone County Court House 700 Bank St, Wallace ID 83873, I am commanded and required to proceed to notice for sale to sell at public auction the real property described in said Order for Sale of Foreclosure and Writ of Execution and to apply the proceeds of such sale to the satisfaction of said Judgment and Decree of Foreclosure with interest thereon and my fees and costs, all payable at time of sale to the highest bidder, for the following described property, situated in Shoshone County, Idaho: 203 W. Mission Ave, Kellogg, ID 83837 and legally described as follows: LOTS 1 AND 2 IN BLOCK 4 OF KELLOGG, SUNNYSIDE ADDITION, ACCORDING TO THE OFFICIAL PLAT THEREOF, FILED IN OFFICIAL RECORDS OF SHOSHONE COUNTY, IDAHO. The sale will be made without covenant or warranty regarding title, possession, or encumbrances to satisfy the obligation of Defendants pursuant to the Judgment entered in this matter, and recorded in the official records of Shoshone County. The real property sold at the sale shall be subject to the redemption rights of redemptioners, as that term is defined in Idaho Code Section 11-402, may redeem the property from the purchaser within six months after the sale, upon paying the purchaser the amount of their purchase, with interest on that amount at the rate allowed by Idaho Code from the date of the sale to the date of redemption, together with the amount of any assessment or taxes which the purchaser may have paid after the commencement of the action and which are not included in the judgment and interest allowed pursuant to Idaho Code Section. In the event the purchaser is a creditor having a prior lien to that of the redemptioners, other than the judgment under which the purchase is made, the purchaser will also be entitled to payment of that lien amount with interest at the rate allowed in Idaho Code Section18-22-104(1). The Sheriff, by Certificate of Sale, will transfer all right, title and interest of the judgment debtors in and to the property at the time of execution of attachment was levied. DATED this 26th day of August, 2021. DEPUTY SHERIFF OF SHOSHONE COUNTY, IDAHO By: Kattie D. Ross NOTE: THE SHERIFF'S OFFICE DOES NOT GUARANTEE CLEAR TITLE OR GUARANTEE CONTINUED POSSESSORY RIGHTS. SHO LEGAL 3953 AD# 483017 SEPTEMBER 7, 14, 21, 2021